Terms & Condition
SMARTWAVE LtdEffective Date: 01/12/2024
Welcome to SMARTWAVE Ltd. These terms and conditions outline the rules and regulations for using our services as an electrical and solar renewables contractor. By engaging our services, you agree to the following terms and conditions.
1. Definitions
• “Company” refers to SMARTWAVE Ltd.
• “Client” refers to the individual or entity entering into an agreement with SMARTWAVE Ltd for services.
• “Services” includes all electrical, solar installation, maintenance, and related renewable energy solutions provided by the Company.
2. Scope of Services
SMARTWAVE Ltd specializes in electrical and solar renewables contracting, including but not limited to:
• Solar panel installation and maintenance.
• Electrical system design, installation, and repair.
• Energy efficiency consultations and upgrades.
Specific deliverables will be outlined in the project proposal or service agreement for each client.
3. Quotations and Payment Terms
• All quotations provided by SMARTWAVE Ltd are valid for [30 days] unless otherwise specified.
• A [percentage deposit] is required to secure the booking and commence work. The remaining balance is payable upon project completion or as outlined in the service agreement.
• Payment methods accepted include [list methods]. Late payments may incur interest at [X]% per month.
4. Project Timeline
• Estimated timelines for project completion will be provided upon agreement. Delays due to unforeseen circumstances (e.g., weather, supplier delays) will be communicated promptly.
• SMARTWAVE Ltd is not liable for delays caused by factors beyond our control.
5. Client Obligations
• Clients must provide accurate and complete information regarding the project site and requirements.
• Access to the property and necessary permissions must be arranged to avoid project delays.
• Clients are responsible for ensuring compliance with any local regulations unless otherwise agreed upon.
6. Warranties and Liability
• SMARTWAVE Ltd provides a warranty for 2 years on workmanship. Product warranties are subject to the manufacturer’s terms.
• The Company is not liable for damages caused by improper use, lack of maintenance, or third-party interference.
• Liability is limited to the value of the contract with the Client.
7. Cancellations and Refunds
• Cancellations must be made in writing. Any deposits paid may be non-refundable depending on the stage of the project.
• Refunds are processed in line with the agreed terms and conditions of the contract.
8. Health and Safety
SMARTWAVE Ltd complies with all applicable health and safety regulations to ensure the safety of our team, clients, and the environment.
9. Intellectual Property
All designs, plans, and documentation provided by SMARTWAVE Ltd remain the intellectual property of the Company unless otherwise agreed in writing.
10. Governing Law
These terms and conditions are governed by and construed in accordance with the laws of [insert jurisdiction]. Any disputes will be subject to the exclusive jurisdiction of the courts in [insert location].
11. Amendments
SMARTWAVE Ltd reserves the right to update or amend these terms and conditions at any time. Clients will be notified of any significant changes.
12. Contact Information
For any inquiries or concerns regarding these terms and conditions, please contact us at:
SMARTWAVE Ltd
14, Wakerley Road, Leicester. Le56aq
Email- info@smartwaveonline.com
